Part Number: 3452

Department of Education Acquisition Regulation

3452.242-71 Notice to the Government of delays.

As prescribed in 3442.7002, insert the following clause in all solicitations and contracts other than purchase orders:

Notice to The Government Of Delays (MAR 2011)

The contractor shall notify the contracting officer of any actual or potential situation, including but not limited to labor disputes, that delays or threatens to delay the timely performance of work under this contract. The contractor shall immediately give written notice thereof, including all relevant information.

(End of clause)